Enforcement Of Contractual Terms (E.G., Flow-Down, Field Verification, Shop Drawing Approval, And No-Damage-For-Delay Provisions)

Laptop next to agreement with pen and glasses

One of our country’s bedrock principles is the freedom of individuals and entities to enter into contracts and rely that their terms will be enforced.

May 4, 2020
David Adelstein - Florida Construction Legal Updates

What you contractually agree to matters, particularly when you are deemed a sophisticated entity. This means you can figuratively live or die by the terms and conditions agreed to. Don’t take it from me, but it take it from the Fourth Circuit’s decision in U.S. f/u/b/o Modern Mosaic, Ltd. v. Turner Construction Co., 2019 WL 7174550 (4th Cir. 2019), where the Court started off by stressing, “One of our country’s bedrock principles is the freedom of individuals and entities to enter into contracts and rely that their terms will be enforced.” Id. at *1.

This case involved a dispute between a prime contractor and its precast concrete subcontractor on a federal project. The subcontractor filed a Miller Act payment bond lawsuit. The trial court ruled against the subcontractor based on…the subcontract’s terms! So, yes, what you contractually agree to matters.

Example #1 – The subcontractor fabricated and installed precast concrete panels per engineering drawings. However, the parking garage was not built per dimensions meaning the panels it fabricated would not fit. The subcontractor had to perform remedial work on the panels to get them to fit. The subcontractor pursued the prime contractor for these costs arguing the prime contractor should have field verified the dimensions. The problem for the subcontractor, however, was that the subcontract required the subcontractor, not the prime contractor, to field verify the dimensions. Based on this language that required the subcontractor to field verify existing conditions and take field measurements, the subcontractor was not entitled to its remedial costs (and they were close to $1 Million). Furthermore, and of importance, the Court noted that the subcontract contained a flow down provision requiring the subcontractor to be bound by all of the terms and conditions of the prime contract and assume those duties and obligations that the prime contractor was to assume towards the owner. While this flow-down provision may often be overlooked, here it was not, as it meant the subcontractor was assuming the field verification duties that the prime contractor was responsible to perform for the owner.

Mr. Adelstein may be contacted at dma@kirwinnorris.com



714.701.9180

Arrange No Cost Consultation

 

Construction Defect Journal is aggregated from a variety of news sources, article submissions, contributors, and information from industry professionals.

No content on this site should be construed as legal advice or expert opinion. By viewing this site you agree to be bound by its terms and conditions

 

Copyright 2020 - Construction Defect Journal – All Rights Reserved