A no-damages-for-delay provision provides significant protection against delay claims under New York law.
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:
NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.
Mr. Wilson may be contacted at wwilson@rc.com