In government contracting, a contractor is entitled to a time extension for “unusually severe weather.” However, this time extension is typically not compensable (meaning you get time, but not additional compensation). However, “a contractor may bring a claim for compensable delay when government delay pushes a contractor’s performance into a period of worse seasonal adverse-but not unusually severe-weather.” Appeals of - Thalle Construction Company, ASBCA No. 63685, 2025 WL 2496328, n.10 (ASBCA 2025) (citation omitted).

In a recent appeal with the Armed Services Board of Contract Appeals, a contractor pursued a weather delay claim. The contractor sought 39 days of adverse weather between the adjusted contract completion date and the actual substantial completion date claiming that the government pushed the contractor’s last 262 days of performance into worse seasonal adverse weather.